A methodology for assessing construction project delays

Construction Management and Economics

Volumn 16, Issue 3, 1998, Pages 327-337

  Bordoli, David W ^a   Baldwin, Andrew N ^b  

^a Merit House   (United Kingdom)

^b LOUGHBOROUGH UNIVERSITY   (United Kingdom)

Author keywords

Claims; Critical path methods; Delay analysis; Project delays

Indexed keywords

TURNAROUND TIME;

CLAIMS; CONSTRUCTION PROJECTS; CRITICAL PATH METHOD; CRITICAL PATHS; DELAY ANALYSIS; INDUSTRY SURVEYS; PROJECT DELAYS; STEP-BY-STEP APPROACH;

CRITICAL PATH ANALYSIS;

EID: 0001164228     PISSN: 01446193     EISSN: None     Source Type: Journal    
DOI: 10.1080/014461998372358     Document Type: Article

References (24)

1. Antill, J.M. and Woodhead, R.W. (1982) Critical Path Methods in Construction Practice, 3rd Edn. Wiley, New York.
2. Aouad, G. and Price, A.D.F. (1994) Construction planning and information technology in the UK and US construction industries: a comparative study. Construction Management and Economics, 12(2), 97-106.
3. Bingham, T. (1996) Worthless work of art. Building, 4 October, 30-31.
4. Cree, C. and Barnes, M. (1989) Quantifying disruption costs. Construction Law Journal, 5, 258-62.
5. Department of Transport (1982) Evaluation of delay and disruption. Letter reference CSE 425/2B/39/02, 26 July 1982.
6. Eggleston, B. (1992) Liquidated Damages and Extensions of Time in Construction Contracts. Blackwell, Oxford.
7. Elliott R.F. (1993) Delay analysis. Seminar papers, Robert Fenwick Elliott.
8. Galloway, P.D. and Nielsen, K.R. (1990) Concurrent schedule delay in international contracts. International Construction Law Review, 7 October.
9. HMSO (1995) Setting New Standards - A Strategy for Government Procurement. HMSO, London.
10. Hughes, G.A. (1983) Building and Civil Engineering Claims In Perspective, 2nd Edn. Longman, London.
11. JCT (1980-1992) Joint Contracts Tribunal For The Standard Form Of Building Contract. Standard form of building contract 1980 edition incorporating amendments 1:1984, 2:1986, 4:1987, 5:1988, 6:1988, 7:1988, 8:1989, 9:1990, 10:1991 and 11:1992 private with quantities. RIBA Publications, London.
12. JJJ (1992) Concurrent delays: the current debate. Building, 20 March, 16-19.
13. Latham, M. (1994) Constructing the Team. Final report of a government/industry review of procurement and contractual arrangements in the UK construction industry. Department of the Environment, UK.
14. Lockyer, KG. (1969) An Introduction to Critical Path Analysis, 3rd Edn. Pitman, London.
15. Lyden, J.M.E. (1993) The law and practice of extensions of time. Construction Law Journal, 9, 16-28.
16. Mastrandrea, F. (1992) Concurrent delays: several solutions. Building, 16 April, 25.
17. Mazerolle, M. and Alkass, S. (1993) An integrated system to facilitate the analysis of construction claims. In Proceedings of the Fifth International Conference on Computing in Civil and Building Engineering. ASCE, California, pp. 1509-16.
18. NEDO (1983) Faster Building for Industry. The Building Economic Development Committee. HMSO, London.
19. Onyango, D. (1993) Reduction of conflicts in construction. MSc report, Loughborough University of Technology, UK.
20. Scott, K.L. (1992) The Management of Contractual Claims: Studies in Contractual Claims. Report, Chartered Institute of Building.
21. Scott, S. (1987) CPM validation of contract claims. Proceedings of the International Conference on Modern Techniques in Construction, Singapore.
22. Trett, R. (1992) Construction delays. Seminar papers. Trett Contract Services Ltd, 1993.
23. Thomas, R. (1993) Construction Contract Claims. Macmillan, London.
24. World Bank (1990) Annual Review of Project Performance Results. World Bank.